CONFIDENTIAL PORTIONS OF THIS DOCUMENT HAVE BEEN DELETED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT.
EXHIBIT 10.49(a)
DESIGN/BUILD AGREEMENT
BETWEEN
AMD SAXONY MANUFACTURING GmbH
AND
MEISSNER + WURST GmbH + CO.
DATED AS OF NOVEMBER 15TH, 1996
PERTAINING TO
DESIGN AND CONSTRUCTION OF AMD FAB 30
DRESDEN, GERMANY
INDEX
Article 1
Scope of Work.................................... 1 1.1 Facility................................................................... 2 1.2 Project.................................................................... 2 1.3 Design And Engineering Services............................................ 2
1.3.1 Engineering Services................................................ 2
1.3.2 Design And Engineering By Contractor................................ 2
1.3.3 Latest Version Of Documents......................................... 4
1.3.4 Process Design...................................................... 4 1.4 Construction And Construction Administration And Supervision Services...... 5
1.4.1 Construction And Construction Management Services By Contractor..... 5
1.4.2 Standards For Completion............................................ 6 1.5 Nature Of Company's Approvals.............................................. 6 1.6 Definitions................................................................ 6
Article 2
Personnel...................................... 8 2.1 Employment By Contractor Of Qualified Personnel............................ 8
2.1.1 Qualified Design Professionals...................................... 8
2.1.2 Qualified Construction Professionals................................ 8 2.2 Contractor's Superintendents............................................... 8
2.2.1 Senior Project Construction Superintendent.......................... 8
2.2.2 Appointment Of Superintendents Required By Law...................... 9 2.3 Construction Personnel..................................................... 9
2.3.1 Supervision Of Construction Personnel............................... 9
2.3.2 Contractor's Responsibility For Personnel........................... 9 2.4 No Relationship With Company............................................... 9 2.5 Company's And Contractor's Representatives................................. 9 2.6 Personnel Proficiency In English........................................... 10 2.7 Employment Of Legal Workers................................................ 10 2.8 Compliance With Law and Promptitude In Hiring And Replacing Personnel...... 10
Article 3
Contract Documents.................................. 10 3.1 Contract Documents......................................................... 10 3.2 Resolution Of Conflicts.................................................... 10 3.3 Language Of Contract Documents............................................. 11
Article 4
Design Documents................................... 11 4.1 Detailed Design............................................................ 11 4.2 Pre-Contract Design........................................................ 11 4.3 Design Development Phase................................................... 11 4.4 Final Design Phase......................................................... 12 4.5 Specifications And Drawings................................................ 12 4.6 Data Sheets................................................................ 12 4.7 Quantities And Recipients Of Design Documents.............................. 12 4.8 As Built Documents......................................................... 12 4.9 Company Not Approving Or Waiving........................................... 13 4.10 Operating Manual........................................................... 13 4.11 Ownership Of Documents..................................................... 13 4.12 Obtaining Permits.......................................................... 13 4.13 Compliance With Code Requirements.......................................... 14
Article 5
Approval of Design Documents............................. 14 5.1 Approval By Company........................................................ 14 5.2 Schedule Of Submittals..................................................... 15
i
5.3 Bulk Orders................................................................ 15 5.4 Return Of Design Documents To Contractor................................... 15 5.5 Nature Of Company's Approval Of Design Documents........................... 15 5.6 Delay By Contractor Or Company In Delivery Of Design Documents............. 16
5.6.1 Delay By Contractor In Delivery..................................... 16
5.6.2 Delay By Company In Delivery........................................ 16
Article 6
Site......................................... 16 6.1 Easements Provided By Company.............................................. 16 6.2 Condition Of Site.......................................................... 16 6.3 Benchmark.................................................................. 17 6.4 Underground Utilities...................................................... 17
Article 7
Acceptance of Site.................................. 17 7.1 Contractor's Inspection Of Site............................................ 17
Article 8
Conduct of the Construction Work.......................... 17 8.1 Construction In Accordance With Approved Design Documents.................. 17 8.2 Parties' Relationship...................................................... 17 8.3 Efficient Administration................................................... 17 8.4 "Build Clean" Protocol..................................................... 18 8.5 Equipment Standby.......................................................... 18 8.6 Construction By Company.................................................... 18 8.7 Compatible Labor........................................................... 18 8.8 Labor Agreement Practices.................................................. 18 8.9 Overtime Labor............................................................. 18 8.10 Identification............................................................. 18 8.11 Commencement And Prosecution Of Construction Work.......................... 19 8.12 Contractor Responsible For Construction Means.............................. 19 8.13 Specialized Construction Manager Required By Law........................... 19 8.14 Sanitation................................................................. 19 8.15 Safety And Security........................................................ 19
8.15.1 Contractor's Responsibility For Safety............................. 19
8.15.2 Safety Program..................................................... 20
8.15.3 Reporting And Investigating Accidents.............................. 20
8.15.4 Reporting Claims................................................... 20
8.15.5 Compliance With State Safety Requirements.......................... 20
8.15.6 Safety Of Tools.................................................... 20
8.15.7 Contractor's Safety Requirements In Facility....................... 20
8.15.8 Security........................................................... 21 8.16 Materials.................................................................. 21
8.16.1 New Materials...................................................... 21
8.16.2 Responsibility For Injury Caused By Equipment...................... 21
8.16.3 Substitution Of Materials.......................................... 21
8.16.4 Materials Objected To By Contractor................................ 22 8.17 Storage Of Materials....................................................... 22 8.18 Cleaning Up................................................................ 22
Article 9
Purchasing Materials, Subcontracting Work and Computers............. 22 9.1 Purchasing Materials....................................................... 22 9.2 Subcontracting Work........................................................ 22
9.2.1 Third Party Subcontracts And Vendors................................ 22
9.2.2 Contractor Bidding On Subcontracted Work............................ 23 9.3 Nature Of Company's Approval............................................... 23 9.4 Contractor Responsible For Subcontractors.................................. 23 9.5 Cost-Plus Subcontracts..................................................... 23 9.6 Computers.................................................................. 24 9.7 Import Requirements........................................................ 24
ii
Article 10
Changes, Additions, and Omissions in the Work.................... 24 10.1 Keeping Account Of Changes................................................. 24 10.2 Proposing And Approving Changes............................................ 24 10.3 Effect Of Change Order On Cost And Timing.................................. 25 10.4 No Effect On Contractor's Other Responsibilities........................... 26
Article 11
Inspection and Testing During Construction..................... 26 11.1 Contractor's Shop Inspections.............................................. 26 11.2 Measurements And Suitability............................................... 26 11.3 Inspection Reports......................................................... 26 11.4 Company's Inspections...................................................... 26 11.5 Company's Inspector........................................................ 27 11.6 Inspection Of Fabrication.................................................. 27 11.7 Testing.................................................................... 28
Article 12
Progress Reports and Progress Monitoring...................... 28 12.1 Progress Schedules......................................................... 28 12.2 Delivery Of Schedules To Company........................................... 28 12.3 Periodic Progress Reports.................................................. 28 12.4 Superintendent's Report.................................................... 28 12.5 Materials Status Reports................................................... 29
Article 13
Accounts and Records................................. 29 13.1 Detailed Accounts.......................................................... 29 13.2 SEMATECH Model............................................................. 29 13.3 Tax Accounting............................................................. 29 13.4 Audit By Company........................................................... 29 13.5 Audit Of Subcontractors And Vendors........................................ 29
Article 14
Time of Completion.................................. 30 14.1 Substantial Completion Date................................................ 30 14.2 Latest Date For Final Completion........................................... 30 14.3 Delays And Extensions Of Time.............................................. 30
14.3.1 Delays Caused By Change Order Or By Company Or By Force Majeure.... 30
14.3.2 Standard For Approving Extensions Of Time.......................... 31 14.4 Delays And Additional Costs................................................ 31
14.4.1 Additional Costs Caused By Company's Delay Or By Force Majeure..... 31
14.4.2 Notice Of Claim For Delay.......................................... 31
14.4.3 Limitation On Costs................................................ 31
14.4.4 Delays By Company In Granting Approvals............................ 31
Article 15
Substantial Completion, Final Completion and Final Acceptance........... 32 15.1 Substantial Completion..................................................... 32 15.2 Final Completion........................................................... 32
15.2.1 Completion Of Punch List Items..................................... 32
15.2.2 Contractor's Certification Of Completion Of Construction Work...... 33 15.3 Final Acceptance And Final Payment......................................... 33
15.3.1 Final Acceptance By Company........................................ 33
15.3.2 Final Payment...................................................... 34 15.4 Release Of Company......................................................... 34
iii
Article 16
Cost of the Work................................... 34 16.1 Basis Of Fee............................................................... 34 16.2 Reimbursable Costs......................................................... 34
16.2.1 Office Costs....................................................... 34
16.2.2 Field Costs........................................................ 37
16.2.3 Excluded Costs..................................................... 41
16.2.4 Principles Affecting Reimbursable Costs............................ 42 16.3 Contractor's Fee........................................................... 43
16.3.1 The Fee............................................................ 43
16.3.2 Calculate Incentive Changes In Fee................................. 43
16.3.3 Fee For Services................................................... 44 16.4 Total Contract Amount...................................................... 44 16.5 Costs Of Alterations....................................................... 44 16.6 Records Of Reimbursable Costs.............................................. 44 16.7 Discounts And Refunds...................................................... 45 16.8 Surplus.................................................................... 45 16.9 Lump Sum Subcontract....................................................... 45 16.10 Adjustment In Fee.......................................................... 46
Article 17
Terms of Payment................................... 46 17.1 Payment Of Contract Amount................................................. 46 17.2 Payment of Increases In Fee; Retainage..................................... 48 17.3 Partial Release Of Retainage............................................... 48 17.4 Payment Not A Waiver By Company............................................ 48 17.5 Payment Of Balance Of Retainage............................................ 48 17.6 Insurance Adjustments...................................................... 49 17.7 Stored Materials........................................................... 49
Article 18
Warranties And Guarantees.............................. 49 18.1 Contractor's Warranty And Guarantee........................................ 49 18.2 Company's Right To Repair.................................................. 50 18.3 Liability For Damages...................................................... 51 18.4 Capacities At Operating Conditions......................................... 51 18.6 Retaining Imperfect Materials.............................................. 51 18.7 No Release Of Other Claims 51
Article 19
Correction of Defective Construction Work....................... 51 19.1 Correction Of Work For Which Contractor Is Responsible..................... 51 19.2 Using New Materials For Repairs............................................ 52 19.3 Repair By Company.......................................................... 52
Article 20
Indemnity...................................... 52 20.1 Contractor's Indemnity..................................................... 52 20.2 Indemnification By Subcontractors And Vendors.............................. 53 20.3 Company's Indemnity........................................................ 53 20.4 Consequential Damages...................................................... 54
Article 21
Insurance And Bank Guarantees............................ 54 21.1 Contractor To Carry Insurance.............................................. 54 21.2 Contractor's Liability Insurance........................................... 55
21.2.1 Liability Coverage................................................. 55
21.2.2 Liability Limits................................................... 55 21.3 Insurance Certificates..................................................... 56 21.4 Company As Additional Insured.............................................. 56 21.5 Builders All Risk Insurance................................................ 56 21.6 Performance And Warranty Bank Guarantees................................... 56 21.7 Advance Payment Bank Guarantees............................................ 57 21.8 Assignment Of Subcontractors' Warranties And Bank Guarantees............... 57
iv
Article 22
Casualty Causing Damage to the Facility....................... 58 22.1 Damage Before Substantial Completion Of Facility........................... 58 22.2 Damage After Substantial Completion Of Facility............................ 58
Article 23
Protection of Property............................... 58 23.1 Contractor's Protection Of Facility........................................ 58
Article 24
Preparation of the Facility for Occupancy and Testing.................. 58 24.1 Contractor's Preparation Of Facility....................................... 58 24.2 Calibration Of Instrumentation............................................. 59 24.3 Take Over For Installation Or Testing...................................... 59
Article 25
System Performance Tests............................... 60 25.1 Conduct Of System Performance Tests; Repairs............................... 60 25.2 Notice Of Satisfactory Completion.......................................... 60 25.3 Coordination Of Systems.................................................... 60 25.4 Standards Of Operation..................................................... 60 25.5 Shut Down Procedure........................................................ 61
Article 26
Use of Completed Portions of the Facility....................... 61 26.1 Use Of Completed Construction Phases....................................... 61
Article 27
Closing Report on Cost of the Facility........................ 61 27.1 Closing Report............................................................. 61
Article 28
Record Documents.................................. 61 28.1 Description Of Record Documents............................................ 61 28.2 Information On Record Documents............................................ 62 28.3 Recording Data............................................................. 62 28.4 Conduits, Pipes, Etc....................................................... 62 28.5 Finalization Of Documents Other Than Drawings.............................. 62 28.6 Finalization Of Drawings................................................... 62 28.7 Remedies Regarding Record Documents........................................ 62
Article 29
Operation and Maintenance Data.......................... 63 29.1 Submittal Of Operation And Maintenance Data................................ 63 29.2 Contents Of Data........................................................... 63 29.3 Data For Equipment And Systems............................................. 63
Article 30
Taxes........................................ 64 30.1 Taxes Assessed Against Facility............................................ 64 30.2 Taxes Affecting Employees.................................................. 64 30.3 Taxes Not Part of Budgeted Cost............................................ 64
Article 31
Liens [Pfandrecht]................................. 64 31.1 Liens [Pfandrecht]......................................................... 64
Article 32
Patents and Confidentiality.............................. 65 32.1 Contractor's Responsibility................................................ 65 32.2 Design Process............................................................. 65 32.3 Replacement Of Infringing Item............................................. 65 32.4 Confidentiality............................................................ 65
v
32.4.1 Proprietary Information............................................. 66
32.4.2 Hold In Confidence.................................................. 66
32.4.3 Announcements....................................................... 66
Article 33
Company's Right to Take Over the Work......................... 67 33.1 Company's Option........................................................... 67 33.2 Reimbursement Of Contractor................................................ 67 33.3 Guarantees................................................................. 67
Article 34
Company's Right to Suspend Work.......................... 67 34.1 Company's Right To Suspend Project......................................... 67 34.2 Suspension Upon Company's Notice........................................... 67 34.3 Compensation For Suspension................................................ 68 34.4 Resumption Of Work......................................................... 68 34.5 Termination Following Suspension........................................... 68
Article 35
Termination for Convenience of Company...................... 69 35.1 Termination By Company..................................................... 69 35.2 Actions Upon Receipt Of Notice............................................. 70 35.3 Guarantees Following Termination........................................... 70
Article 36
Default by the Contractor............................... 70 36.1 Events Of Default.......................................................... 70 36.2 Company's Right To Take Over Work.......................................... 71 36.3 Company's Right To Complete Work........................................... 71 36.4 Contractor's Action Upon Receipt of Notice................................. 71 36.5 Remedies Cumulative........................................................ 72 36.6 Limits On Amount Payable To Contractor..................................... 72
Article 37
Penalty Clause................................... 72 37.1 Damages For Delay In Substantial Completion Of Facility.................... 72 37.2 Payment Of Contract Penalty................................................ 72 37.3 Subcontract Penalty Clauses................................................ 72 37.4 Set-Off Of Contract Penalties.............................................. 72
Article 38
Compliance with Laws, Choice of Law, Choice of Forum, Contract Language.... 73 38.1 Compliance With Applicable Law............................................. 73 38.2 Indemnity For Violation.................................................... 73 38.3 Choice of Law.............................................................. 73 38.4 Disputes; Arbitration...................................................... 74
38.4.1 Resolution Of Disputes By Arbitration.............................. 74
38.4.2 Place Of Arbitration............................................... 74
38.4.3 Exclusive Jurisdiction............................................. 74
38.4.4 Selection Of Arbitrators........................................... 74
38.4.5 Language Of Proceedings............................................ 75
38.4.6 Applicable Law..................................................... 75
38.4.7 Arbitration Award.................................................. 75
38.4.8 Provisional Remedies............................................... 75 38.5 Contract Made In English................................................... 75
Article 39
Financing of Project................................ 75 39.1 Take Over By Project Lender................................................ 75 39.2 Approvals By Project Lender................................................ 75 39.3 Audit By Project Lender.................................................... 75 39.4 Amendment of Agreement..................................................... 76
vi
Article 40
Force Majeure.................................... 76 40.2 Effect On Ti ...
*End of Preview*
Click the 'Add to Cart' button to download the complete and formatted agreement.